Welcome to SolarBoard Ltd ("SolarBoard Ltd", "we", "our" or "us"). These Terms and Conditions govern your access to and use of our website, www.korglobalenergy.com, and all related services, including energy consultations, enquiries, quotations, project discussions, product enquiries, and installation support.
By using this website, you agree to these Terms and Conditions. If you do not agree, please do not use the website or request services from us. We may update these Terms from time to time, and the latest version will apply whenever you access the site.
1. Company information
SolarBoard Ltd is a renewable energy and infrastructure business serving homes, businesses, institutions, and communities across Nigeria. Our services include solar power systems, backup power solutions, energy auditing, security and safety systems, fire protection, general contracting, and technical support.
2. Service enquiries and proposals
All product, pricing, and project information on this website is provided for general information only. Any quotation, consultancy advice, estimate, or project proposal is subject to confirmation after review of site conditions, technical requirements, load analysis, regulatory issues, and cost assumptions. We reserve the right to amend or decline any enquiry or proposal at our discretion.
3. Payments and project execution
Where a project is accepted, the agreed payment schedule, delivery timeline, installation plan, and project responsibilities will be documented in the relevant contract, quotation, or order confirmation. SolarBoard Ltd may require a deposit or milestone payment before work begins, depending on the scope of the project. Any changes requested by the client after proposals are accepted may affect price, delivery time, and installation schedules.
4. Site work and timelines
We will make reasonable efforts to complete projects within the agreed timeline. However, delivery, installation, and commissioning may be delayed by weather, sourcing conditions, logistics, local site constraints, supply chain disruptions, government approvals, or force majeure events beyond our reasonable control. We will communicate such delays as soon as we are able and will not be liable for indirect or consequential losses arising from delay where we have acted reasonably.
5. Warranties and support
Equipment and systems supplied by SolarBoard Ltd are covered by the manufacturer’s warranty and/or our workmanship warranty where applicable. We provide technical support and maintenance services in line with the agreed contract. Warranties do not cover misuse, tampering, improper installation by third parties, acts of God, or damage caused by external power conditions, vandalism, or non-compliance with service instructions.
6. Website content and intellectual property
All content on this website, including text, graphics, logos, images, product information, and design elements, is the property of SolarBoard Ltd or its licensors and is protected by intellectual property laws. You may browse, share, or print content for personal non-commercial use only. You must not copy, reproduce, redistribute, modify, or commercially exploit any part of the website without prior written permission.
7. Limitation of liability
SolarBoard Ltd makes every effort to ensure the accuracy of information on this website, but we do not guarantee that the information is complete, error-free, or always up to date. We shall not be liable for any loss, damage, or inconvenience arising from the use or inability to use the website, including indirect, special, incidental, or consequential damages, except where required by law.
8. Governing law
These Terms are governed by the laws of the Federal Republic of Nigeria. Any dispute arising from these Terms or the services we provide shall be subject to the jurisdiction of the courts in Nigeria, unless otherwise agreed in writing.
If you need further clarification, contact us at info@korglobalenergy.com or call us on +234 803 7304 133 / +234 802 5808 727.
